200405934 - Laserfiche WebLink

Browse

200405934 12.6 Construction Change Directives: In the event the Contract Documents provide for Construction Change Directives or similar mechanisms for changes in the Work, Trade Contractor shall comply with all requirements of the Contract Documents with respect thereto. SECTION 13 Mechanic's Liens or Claims 13.1 Trade Contractor's Duty to Discharge Liens or Claims: If any subcontractor, laborer, materialman or supplier of the Trade Contractor or any other person directly or indirectly acting for, through or under it or any of them files or maintains a lien or claim, whether a mechanics' lien, stop notice or an attested account or otherwise, against the Project or premises of the Project or any part thereof or any interests therein or any improvements thereon or against any monies due or to become due from the Owner to SIGNATURE or from Owner to Trade Contractor, for or on account of any work, labor, services, materials, supplies, equipment or other items performed or furnished for or in connection with the Work or under any Change Order or supplemental written agreement for extra or additional work -in connection with the Project, the Trade Contractor shall cause such liens and claims to be satisfied, removed or discharged at its own expense by bond, payment or otherwise within ten (10) days from the date of the filing of such liens or claims, and upon its failure to do so SIGNATURE shall have the right, in addition to all other rights and remedies provided under this Trade Contract and the Contract Documents, or by law, to cause such liens or claims to be satisfied, removed or discharged by whatever means the Owner or SIGNATURE chooses, at the entire cost and expense of the Trade Contractor (such cost and expense to include legal fees and disbursements). The Trade Contractor shall defend, indemnify, protect and hold harmless SIGNATURE and the Owner from and against any and all such liens and claims and actions brought or judgments rendered thereon, and from and against any and all loss, damages, liability, costs and expenses, including reasonable attorneys' fees and disbursements, which SIGNATURE and/or the Owner may sustain or incur in connection therewith. SECTION 14 Compliance with Law and Permits 14.1 Trade Contractor shall comply with all Federal, State, Municipal and local laws, ordinances, codes, rules, regulations, standards, orders, notices and requirements, including, but not limited to, those relating to safety, discrimination in employment, fair employment practices or equal employment opportunity without additional charge or expense to SIGNATURE and, at its own cost and expense, shall correct any violations thereof resulting from or in connection with the performance of its Work. At any time, upon demand, Trade Contractor shall furnish such proof as SIGNATURE may require showing such compliance and the correction of such violations. The Trade Contractor shall defend, hold harmless and indemnify SIGNATURE from and against any and all loss, injury, claims, actions, proceedings, liability, damages, fines, penalties, costs and expenses, including legal fees and disbursements, caused or occasioned directly or indirectly by the Trade Contractor's failure to comply with any of said laws, ordinances, rules, regulations, standards, orders, notices or requirements or to correct such violations. SECTION 15 Labor Relations 15.1 Control Over Employees: Trade Contractor shall maintain control over all its employees, subcontractors, suppliers and others for whom Trade Contractor is responsible and shall remove or cause to be removed from the Project any person or entity for whom Trade Contractor is responsible who is determined by the Owner, the Architect or SIGNATURE to be detrimental to the Project. To the fullest extent permitted by law, Trade Contractor shall do whatever is reasonably necessary to assure harmonious labor relations and shall not employ any person who wrongfully causes, or who is likely to wrongfully cause, strikes, work stoppages or other actions detrimental to the Project. 15.2 Strike: In the event of a strike, picketing or other actions resulting from Trade Contractor's Work, after forty-eight (48) hours notice to Trade Contractor, SIGNATURE may take any lawful steps necessary to complete Trade Contractor's Work. Trade Contractor shall take all lawful necessary action to terminate any strike or picketing. If SIGNATURE establishes a gate reserved for use by Trade Contractor (and any other Trade Contractor with whom a labor dispute exists), Trade Contractor will use such gate and continue its Work without interruption or delay. Initial / 13