|
79--~G3~$~ ~
<br />set forth in Paragraph t.i as may be required in conrec-
<br />don with the replacement of such Work,
<br />].3.74 Providing, professional services made necessary
<br />by the default of the Contractor or by major defects in
<br />the Work of the Contractor in the performance of the
<br />Construction Contract.
<br />].3.tj Preparing a set of reproducible record prints of
<br />drawings showing significant changes in the lh•`ork made
<br />during the construction process, based on marked-up
<br />prints, drawings ant! other data famished by the Conirac-
<br />t~• to the Architect.
<br />1.3.76 Providing extensive assistance in the utilization
<br />of any equipment or system such as initial swrt-up or
<br />testing, adjusting and balancing, preparation of operation
<br />and maintenance manuals, training personnel for opera-
<br />. lion artd maintenance, and consuRation during operation.
<br />t.3.t7 Providing services after issuance to the Owner of
<br />the final Certificate for Payment.
<br />],3.]8 Preparing to serve or serving as an expert witness
<br />in connection with any public hearin;{, arbitration pro-
<br />weding or legal proceeding.
<br />7.3.'9 ?roviding services of professional consultants for
<br />oti+er than the normal structural, mechanical and rledr.-
<br />ca! engineering services for the Project.
<br />1-}38-•?raviding• •-n++t- erthc r x+~-'reel ~+et-nthrnv;se•-in-
<br />e+vefed-iMi~: Agxr+nrnl-ex-ms~tv?Mmerir Frrni-.lied-in
<br />aeeortlan+4!-•s.+t1r-grneneFfreeeepted-asc:`~itecta,u= flc.ctite
<br />ARTICLE 2
<br />7f-lE OWNER'S RESPON51131LiT1E5
<br />2.7 The Owner shall provide fait information, including
<br />a complete program, regarding his requirements for the
<br />Pro}est.
<br />z.2 The Osvner shall designate, when necessary, arep-
<br />resentative authorized to act in his beha(t wlt~ respect ro
<br />the Project The Owner shad examine documens seb-
<br />miued by the Architect and shall render decisions per-
<br />taining thereto promptly, to avoid unreasonable delay in
<br />the progress of the Architect's services.
<br />3.3 Tfie Owner shah f{irnisfi a certified 'and survey of
<br />the site giving, as applicable,-grades and lines of strt•rts,
<br />a.!eys, pavements and adjoining property; rights-of-way,
<br />tcsuictioas, easements, encroachments, zoning, dreci re-
<br />strictions, boundaries and contours of the site; tocatior.s,
<br />dimensions and complete data pertaining to existing
<br />buildings, other improver+ents and trees; and fu!; irfor-
<br />mation tor.[erning oval"able servile and u;~'.ity nes both
<br />public and private, aboee and beincv grade, :nc'udi^g
<br />inverts and depths.
<br />2i The Owner shall furnish the seroin•s of a se?s cngi-
<br />neer or other consultant alien such services are deemer.
<br />nectssary by the Architect, including rcpt rs, test ur•ngs,
<br />lest pits, snit bearing values, pereolat;on ;gists, air anr!
<br />water pollution tess, ground corrosior. and resistivity
<br />test, acrd oilier necessary operations for determin?ng sub-
<br />sn•~, air and water conditions, witfi apprgpr;ate aro`es-
<br />sipndl iCCOmmendatiOnS.
<br />r~
<br />2.5 The Owner s!ra') furnish structural, mechanical,
<br />chemical and other hrburatory tests, inspections and re-
<br />ports as required by law or the Contract Documents.
<br />2.6 The Owner shat: famish such Iega1, accouming, and
<br />insurance counseling sen~ices as may be necessary for the
<br />Project, and such audrGng services as he may rrctuire to
<br />ascertain how or for v~hat purposes tltie Contractor has
<br />used the moneys paid to him under the Construction
<br />Contra Ct.
<br />2.7 The services, information, surveys and reports re-
<br />quireri by Paragraphs 2.3 through 2.G inclusive shall be
<br />furnished at the Owner's expense, and the Architect shall
<br />be entitled to rely upon the accuracy and completeness
<br />thereof.
<br />2.¢ If the Owner becomes aware of any fault or defect
<br />in the Project or non-conformance with the Contract
<br />Documents, he shall glue prompt written notice thereof
<br />to the Archie^ct.
<br />2.4 The Owner shad furnish information required of him
<br />as espeditious!y ..s necessary for the orderly progress of
<br />the l:'ork.
<br />ARTICLE 3
<br />CONSTRUC.TiON COST
<br />3.1 If the Construction Cast is to 6e used as the basis
<br />for determining the Architect's Compensation for Sasic
<br />Services, i; shall be the tutu( cast or esYmated Cost to
<br />the Uwner o' a!I Work designed or specified by the
<br />Architect. The Construction Cost shall be determined as
<br />follows, with precedence in the order listed'
<br />3.t.7 Fer comp;reed construction, the cost of all such
<br />Work, including coos of managing construction;
<br />3.7.2 For Work not constructed, tt) the lowest bona fide
<br />bid received from a qualified bidder for any or ail pf such
<br />Work, or (z) if the Work is not bid, the bona fide nego-
<br />:;ated proposal submitted for any or all of such Wprk; or
<br />3.7.3 For \work for which no such bid or proposal is
<br />received, ?') the latest Detailed Estimate of Consuuctipn
<br />Cost if ene is availab'e, er Q) the latest Statement of
<br />Probable Cnnstruc:Ian Cust.
<br />3.2 Construction Cost does not include the compensa-
<br />tion of the Architect one! his consultants, the cost of the
<br />;and, rights-uf-way, or other costs which. are the responsi-
<br />hi!ity of the Owner as provided in ?aragraphi 2.3 through
<br />2.G inclusive.
<br />3.3 The cost of la`+or, materials and cqu~pment furnished
<br />by the U,vr,er for the Project shat! be included in the
<br />Construction Cost at current market rates including a
<br />reuonaisle allowance for overhead and profit.
<br />3.a Statements of Probab:e Construction Cost and fle-
<br />ta:;ed Cost Fst~mates prepared by the Architect represent
<br />his best jur'gment as a design professional familiar with
<br />the costruct:;m industry. i; is recognized, however, that
<br />nr.ther t`~e Arc`,itet't nor the Owner has any conirot over
<br />the cos: of lahur, ma•~ri; rs o. equipment, over the con-
<br />'ra~•o~,- mr•~hor?s t,f .^'everm:ning bid prices, or over com-
<br />~e'~':ve h:cc•n;; or r-t~rKe: tondrtionz- Accordingly, the
<br />A!A UK3CUME.~`7 Brat CSiV\FR-ARCttt?'r~T AC;::E E.+?E\' • jA\'_'ACY !".. .;;i` A'A=~' t;,'. J7<
<br />.n' Avt!tilCA': ir:STt7tttr {)r ,12CI n7EC ts. 7'S; vr'.v Y(yRK At-r., '~.s{,•.. 1'..4,'"\!.'t ~\, J.C. 2tx~OG
<br />
<br />
<br />
<br />
|